WorldBridgeMedia.com and all associated sites, products, and services are a project of Foundation for Noöspheric Consciousness, a Private Ministerial Association.
FOUNDATION FOR NOÖSPHERIC CONSCIOUSNESS – A Private Ministerial Association
TERMS OF SERVICE
By joining Foundation for Noöspheric Consciousness, a Private Membership Association and/or any website or Social Media Group started by, created by, maintained, or organized by the Association, I agree to the terms and conditions of Foundation for Noöspheric Consciousness, a Private Membership Association, Agreement as follows.
1. This Association of members declares that our objective is to allow the Private Membership Association founders and all Private Membership Association members with a platform in which to conduct all manner of private business with the Association and with other Associations and Association members, keeping all business in the private domain and utilizing the protections guaranteed by the Universal Declaration of Human Rights (UDHR), the Constitution to conduct business in private and to provide a platform for members to conduct business in the private domain under all protections acknowledged and guaranteed by the Constitution of the UNITED STATES, and any previous protections guaranteed.
2. We believe that the Holy Scriptures, the Universal Declaration of Human Rights (UDHR), the Constitution of the United States of America, the various constitutions of the several states of the union, and the Charter of Rights of Canada guarantees our members the rights of absolute freedom of religion, free speech, petition, assembly, and the right to gather together for the lawful purpose of helping one another in asserting our rights protected by those Constitutions, Charter and Statutes, in addition to the rights to be free from unreasonable search and seizure, the right to not incriminate ourselves, and the right to freely exercise all other unalienable rights as granted by our creator, our almighty God and guaranteed by those Constitutions, Charter, and Statutes.
WE HEREBY Declare that we are exercising our right of “freedom of association” as guaranteed by the Universal Declaration of Human Rights (UDHR), the U.S. Constitution and equivalent provisions of the various State Constitutions, as well as the Charter of Rights of Canada. This means that our Association activities are restricted to the private domain only and outside of the jurisdiction of government entities, agencies, officers, agents, contractors, and other representatives as provided by law.
3. We declare the basic right of all of our members to decide for themselves which Association members could be expected to give wise counsel and advice concerning all matters including, but not limited to education, physical, spiritual, and mental health care assistance, law, and any other matter and to accept from those members any and all counsel, advice, tips, whom we feel are able to properly advise and assist us.
4. We expect the freedom to choose and perform for ourselves the types of therapies and treatments that we think best for diagnosing, treating, and preventing illness and disease and for achieving and maintaining optimum wellness, as well as the freedom to choose for ourselves any types of assistance which may be made regarding law and any other private business activity.
5. The mission of this Association is to provide members with a forum to conduct business between members in the private domain with the protections guaranteed within the aforesaid Constitution and Charter remaining fully intact.
6. The Association will recognize any person(s), natural or otherwise (irrespective of race, color, or religion) who have joined this Association or any social media group organized, created, or managed by this Association and is in agreement with these principles and policies as a member of this Association, providing said person has not been sanctioned, exercised, or otherwise banned by the association, and will provide a medium through which its individual members may associate for actuating and bringing to fruition the purposes heretofore declared.
7. Membership to this Association, “Foundation for Noöspheric Consciousness”, and any of its groups may be terminated by the association Trustees or their designee, at any time, should they conclude that a specific member is interacting with them or any other members in a way that is contrary or detrimental to the focus, principles, and betterment of this Association.
8. I understand that, since The Association is protected by the First and Fourteenth Amendments to the U.S. Constitution, it is outside the jurisdiction and authority of Federal and State Agencies and Authorities concerning any and all complaints or grievances against The Association members or other staff persons. All rights of complaints or grievances will be settled by an Association designee, committee, or tribunal and will be waived by the member for the benefit of The Association and its members. By agreeing to this membership form I agree that I have sought sufficient education to determine that this is the course of action I want to take for myself.
9. I agree to join Foundation for Noöspheric Consciousness, a private membership association under common law, whose members seek to help each other achieve better health and good quality of life.
(A) I am voluntarily changing my capacity from that of a public person to that of a private member.
My activities within The Association are a private contractual matter that I refuse to share with the Local, State, or Federal investigative or enforcement agencies. I fully agree not to pursue any course of legal action against a fellow member of The Association, unless that member has exposed me to a clear and present danger of substantive evil, and upon the recommendation and approval of the Association.
10. I enter into this agreement of my own free will without any pressure or coercion. I affirm that I do not represent any Local, State or Federal agency whose purpose is to regulate and approve products or services, or to carry out any mission of enforcement, entrapment or investigation. I have read and understood this document, and my questions have been answered fully to my satisfaction. I understand that I can withdraw from this agreement and terminate my membership in this association at any time, and that my membership can and will be revoked if I engage in abusive, violent, menacing, destructive or harassing behavior towards any other member of The Association. These pages consist of the entire agreement for my membership in The Association.
I agree this contract began on the date of my joining “Foundation for Noöspheric Consciousness”. I declare that by joining this Association and/or the Associations websites and/or social media group(s), I have carefully read the whole of this document and I understand and agree with it.
PLEASE READ CAREFULLY
TERMS & CONDITIONS
Please take time to READ through thoroughly and ensure you fully understand these terms and conditions, as this pertains to the Agreement of your registration with any of the products or services sold via donation (sometimes referred to as “Projects”) by Foundation for Noöspheric Consciousness in association with WorldBridge Media (sometimes referred to as “Ministry”, “WorldBridge Creative”, “WorldBridge”, “WB”, “We”, “Us”, “Our”, “the designer”, “the producer”, “the editor”, and “the consultant”).
By purchasing our products or services via donation or interacting with free consulting, you (sometimes referred to as “Member”, “the user”, “the client”, and “you”) agree to the following terms stated. Please contact us if you do not understand any of the terms or conditions in this document.
PURPOSE
This Association is created and organized to operate within the private domain as a Private Membership Association. The purposes for which it is organized are set forth in the Articles of Association, and in part are as follows: To allow the Private Membership Association founder and all Private Membership Association members with a platform in which to conduct all manner of faith-based private business, ministry, education, and services or assistance with the Association and with other Associations and Association members, keeping all business in the private domain and utilizing the protections guaranteed by the Universal Declaration of Human Rights, the Constitutions, and the Charter of Rights, to conduct business in private, remaining outside of the jurisdiction of regulation imposed upon legal fictions by government entities and Public Law.
To provide a resource for members to seek, and access, all manner of education, information, services, advice, council, and support consistent with our religious and spiritual freedoms as guaranteed by the Constitution of the United States of America, the Constitutions of the individual states of the union, and the laws of the United States; To conduct all manner of ministry and any manner of business within the private domain as seen fit by the Association founders and Trustees.
The Spiritual Association/Church/Ministry defined by this Declaration is organized for worship, educational, spiritual freedom, faith and reliance upon nature, and beneficent purposes, and is established under the exclusive jurisdiction of the Ecclesiastical Law of Foundation for Noöspheric Consciousness, for furthering the uplifting and enlightenment of all people who voluntarily choose to associate with this Ministry throughout the World and the betterment of life on planet Earth. Foundation for Noöspheric Consciousness must always remain an unincorporated Ministry dedicated to this purpose.
HOURS
Scheduled operating hours are between 9 am and 6 pm PST Monday through Friday. WorldBridge Media is closed on weekends and national holidays.
TURNAROUND TIMES
WorldBridge Media’s standard turnaround is 7-10 business days (Monday-Friday) from the time we receive both your invoice approval and deposit payment donation. This is our average turnaround and is based on customer needs and the current production schedule, and it is not guaranteed unless a specific in-hand date was discussed prior to approvals. If you need your project by a specific date, please let us know in advance, as this may require a rush fee if that date does not fall within our standard turnaround. Please note, that we are not open for national holidays and these days will add to the turnaround time of your order.
PROJECTS
Foundation for Noöspheric Consciousness and WorldBridge Media agree to provide services which may include: website design, graphic/logo design, video/film editing, music production, pitch deck creation, copywriting, copyediting, book publishing, social media marketing, and creative & technical consulting, to help Members connect Consciousness, Culture & Community, through compelling visual design, intuitive media production, and coherent communication. If you have any questions you would like to discuss, please do so at the beginning of the project, otherwise, members agree to abide by all policies and procedures outlined in this Agreement as a condition of their participation in any of our projects. Unless otherwise stated, these policies form the basis of every/all contract between WB and our clients.
FINANCIAL OBLIGATION
Members are responsible for the completion of all payment plans associated with products or services they purchase via donation. We reserve the right to seek recovery of any monies remaining unpaid via our Collection Agency. Member understands that lifetime access to any programs will be forfeited with no refund if Member does not complete all donation payment plans. Member understands that lifetime access to any projects is a gift granted by the trustees of Foundation for Noöspheric Consciousness and may be revoked at any time without notice based on trustee’s discretion.
METHODS OF PAYMENT
We accept Visa, Mastercard, and American Express as a form of payment donation. If Member chooses to pay donation by monthly installments, he/she authorizes the monthly charge for the product on the Member’s credit card or debit card.
REFUNDS
Due to the nature of online media services and creative consulting, there are no refunds (with the exception of specific Projects when indicated).
PLEASE NOTE: All refunds are discretionary as determined by Foundation for Noöspheric Consciousness and WorldBridge Media. If you have any questions, contact us at info@worldbridgemedia.com.
DONATIONS
Foundation for Noöspheric Consciousness and WorldBridge Media are an establishment of an UNINCORPORATED PRIVATE MINISTERIAL ASSOCIATION AND SPIRITUAL CHURCH MINISTRY. All purchases of products or services with WorldBridge Media and Foundation for Noöspheric Consciousness are by donation, gift, or contribution, and therefore 100% tax-deductible write-offs. You can save your receipts and write off 100% of the cost of your purchases from “Foundation for Noöspheric Consciousness” on your annual taxes.
ESTIMATES & QUOTES
All quotes are based on time/project estimates and may be subject to change if additional work is required.
OVERTIME: If projects exceed the time estimated, you will be billed for the extra time. The first 8 hours of extra time will be charged at 1.5X our regular hourly rate. After 8 hours of overtime work, you will be charged 2X our regular hourly rate.
RUSH FEE: A rush fee is applied to any project/deliverable that requires weekend work hours, and/or any project/deliverable with a deadline of 48 hours and under. The rush fee for any project/deliverable is an additional 25%-50% of the total cost of that project/deliverable, depending on the urgency. The rush fee will be applied to the total amount.
Our ability to rush an order depends on our current production schedule, and while we do our best to offer this service at all times, occasionally we will not be able to accommodate any rush order. Please notify us of your project deadline as soon as possible when requesting a quote and we can review all options.
SCOPE: Changes requested beyond the original scope of the project will be charged at an hourly rate or the fee appropriate to the request.
WorldBridge Media has the commitment to clear communication with our clients. We will communicate with you prior to incurring overtime, rush, or scope-related charges.
If you are late for a meeting with our team, you lose that time. If you do not show up, you will still be charged in full.
THE PAUSE CLAUSE
If a client deliverable (such as content, approvals, or donation payment) is more than 10 business days late, the project will be considered “on hold.” Once the deliverable is received by WorldBridge Media and the project is reactivated, it will be rescheduled based on our current workload and availability. Just be aware, it could be weeks or even months to be back on the calendar if your project is put on hold. WorldBridge Media will notify you if the Pause Clause is activated.
BILLING
A non-refundable fee of 50% is required upfront as a deposit for our services. We will not begin work until this deposit fee is paid in full unless otherwise approved by WorldBridge Media staff.
The remaining 50% will be due upon completion of the project. Please note, additional charges assessed in the process of completing the project, job, or task, may be added to, and reflected in, the final invoice amount.
Websites will be launched & transferred to the client once the final donation payment is received. All projects submitted for final approval will bear a WB watermark (or audio mark). Upon receipt of the final donation payment, a final version without a watermark (or audio mark) will be delivered to the client.
Invoices from WorldBridge Media are due within 10 days of the client’s receipt of the invoice. At WorldBridge Media’s discretion, unpaid balances beyond 10 business days will incur a percentage-based late payment fee. Balances 11 – 30 days past due will incur a 10% fee. Balances past due beyond 31 days will incur an additional 5% fee per 30 days.
STOCK & EXPENSES
STOCK PHOTOGRAPHY, STOCK VIDEO & STOCK GRAPHICS will be purchased and costs will be billed to the client. Otherwise, the client will be required to obtain the photos and graphics through their own means.
Any stock photography and/or graphics required for inclusion in the client’s website or design work remain the property of WorldBridge Media and may be used in multiple, separate projects. Should the client require full ownership of the provided photography or graphics, these terms must be disclosed in writing. WB will charge per hour for the time for finding stock photography and graphics and will bill the expenses to the client with a markup fee.
EXPENSES: WB will bill any expenses for the project to the client and will charge a markup for time on top of every expense.
SERVICES
GRAPHIC & LOGO DESIGN: We use Adobe CC products, including Illustrator, Photoshop, and InDesign, for graphic design, logo design, book layout, and publishing projects. Standard graphic designs such as business cards or flyers include 2 revisions at no extra charge. Additional revisions require an extra charge. Please note, original logo designs are billed as a separate charge and are not included as part of other design projects such as website design and pitch deck design.
PITCH DECK DESIGNS: We design pitch deck presentations that include 2 revisions per page at no extra charge. This is also known as a startup pitch deck or slide deck. It is a visual document that provides investors with essential information about your business plan, product or services, fundraising needs, and key metrics like valuation, target market, and financial goals. There will be extra charges if any projects exceed the initial 5 pages for a deck, and/or need additional revisions per page.
WEBSITE DESIGNS: We perform website design using WordPress CMS. We are adept with HTML5 and CSS coding. We will make your site responsive, for all digital platforms. Our websites are designed to work with current technologies and browser versions. If future unforeseeable changes to technology or browsers cause website errors, WorldBridge Media can repair these, quoted at the standard hourly rate.
VIDEO/FILM EDITING: For film and video editing projects, we use Adobe Premiere Pro, primarily. We also do light motion graphics and visual effects using Adobe After Effects.
MUSIC PRODUCTION: We offer a range of music production, composition, and songwriting services. We primarily use Logic Pro X for production, recording, and editing.
SOCIAL MEDIA MARKETING: We work with clients to develop social media marketing strategies specific to their needs, including copywriting, scheduling, and analytics while keeping up-to-date on trends and technology.
CREATIVE & TECHNICAL CONSULTING: Through client consultation, we listen and learn about your creative vision, and offer our perspective and technical suggestions to help you bring your vision to life.
Plugins that are installed in our website designs will be checked, to the best of our ability, to ensure they are working properly; however, if they malfunction later, we will not be held responsible. If your website is experiencing plugin malfunction, WorldBridge Media staff will look into resolving the issue, based on an hourly technical consulting rate.
Quoted delivery dates may change due to unforeseen circumstances, delays in client response times, or excessive design changes.
It is understood that WorldBridge Media is an independent professional contractor and will not, in any event, be construed as or held to be an employee of the customer. It is further agreed that at no time will we or any work efforts be under the supervision or control of the customer, although we agree to comply with all reasonable requests and regulations applicable to any other business invitation. It is also agreed that WB, as an independent contractor, is not restricted to working exclusively for the customer during the term of the agreement.
Ownership of any graphic designs, development ‘code’, websites, video files, audio productions, and recordings remain the property of WorldBridge Media until such time as all final donation payments are received.
Work that is refused by you, or remains unpaid will remain WB’s property and cannot be used in whole or in part by you or your company.
WorldBridge Media will not be responsible for any damage, loss, or liability the client or any third party may suffer. This includes loss of revenue, profits, or data resulting from delays, non-deliveries, wrong delivery, and any and all service interruptions caused by WB or otherwise.
DESIGN CREDIT & PROMOTION
DESIGN CREDIT: A link to WorldBridge Media will appear in either a small type or a small graphic at the bottom of the Client’s website. If a graphic is used, it will be designed to fit in with the overall site design. If a client requests that the design credit be removed, a nominal fee will be applied. The Client also agrees that the website developed for the Client may be presented in WB’s portfolio.
PROMOTION: The designer retains the right to reproduce, publish, and display the deliverables in the Designer’s portfolios and websites, in galleries, design periodicals, and other media or exhibits for the purposes of recognition of creative excellence or professional advancement, and to be credited with authorship of the deliverables in connection with such uses. Promotional Approval: Either party, subject to the other’s reasonable approval, may describe its role in the Project on its website and in other promotional and marketing materials, and, if not expressly objected to, include a link to the other party’s website.
CONFIDENTIALITY
Foundation for Noöspheric Consciousness and WorldBridge Media respect Member privacy and insist that the Member respects ours as well. Thus, consider this a mutual non-disclosure Agreement. Any confidential information shared by WorldBridge Media and Foundation for Noöspheric Consciousness Members or any representative of WorldBridge Media and Foundation for Noöspheric Consciousness is confidential, proprietary, and belongs solely and exclusively to the Member or representative who discloses it. Parties agree not to disclose, reveal, or make use of any confidential information or any transactions during discussions, in the forum, or otherwise.
Member agrees not to use such confidential information in any manner other than in discussion with other Members, Foundation for Noöspheric Consciousness, or WorldBridge Media, during the respective program. Confidential information includes, but is not limited to, information disclosed in connection with this Agreement, and shall not include information rightfully obtained from a third party.
Both Parties will keep private information in the strictest confidence and shall use their best efforts to safeguard the confidential information and to protect it against disclosure, misuse, espionage, loss, and theft.
Member agrees not to violate the Publicity or Privacy Rights belonging to WorldBridge Media and Foundation for Noöspheric Consciousness, furthermore, Member will NOT reveal any information to a third party obtained in connection with this Agreement or our direct or indirect dealings with Member, including but not limited to, names, email addresses, third-party company titles or positions, phone numbers, or postal addresses. Additionally, Member will not, at any time, either directly or indirectly, disclose confidential information to any third party.
By purchasing our products via donation, you agree that if you violate or display any likelihood of violating this Agreement, WorldBridge Media and Foundation for Noöspheric Consciousness and/or the other Member(s) will be entitled to injunctive relief to prohibit any such violations to protect against the harm of such violations.
PROFESSIONAL COURTESY
WorldBridge Media takes pride in professional courtesy and manners and hopes our clients do too. “The Client” agrees to behave through all communications in a professional, courteous, and respectful manner towards designers and staff at WBM. Any actions deemed by us as disrespectful, unprofessional, abusive, or verbal/written cruelty on the part of “The Client” may result in cancellation of the project, and the deposit will serve as a cancellation fee, along with a prorate payment via donation based upon the time spent if that time exceeds 50% of the quoted work.
Actions that may result in the cancellation of the project may include: insulting language, profanity, unwarranted criticism of the designer’s general ability, disrespectful comments, personal insults, swearing, blaming on social media sites, threats not to pay for the work for unwarranted reasons, and general lack of respect. Please note: It would be extremely rare for WB to use this clause, and the client behavior would have to be extreme and affect other areas of our staff and designers’ work.
CANCELLATION
DESIGN: Any design services (branding, collateral, web) will forfeit the non-refundable deposit and any additional hours worked will be billed, as well as any additional expenses or fees.
If canceled:
- All materials delivered in connection with the project must be returned.
- Use of work done in connection with the project without consent could result in additional fees or legal action.
- All original artwork and digital files prepared in connection with the project belong to WorldBridge Media.
Either party may terminate our contract without cause upon thirty (30) days with written notification to the other party. We may terminate this agreement immediately upon the refusal to, or inability to, perform under the contract or a breach of the contract. On termination of the contract, your obligation to pay WB, except for services already accrued or incurred, will forthwith cease and terminate.
COMPLETION
In the estimate provided for your project, we provide the estimated time it will take to be completed. This time frame may be longer if you fail to provide content in a timely fashion. The time frame does not start until a deposit is made, and sites will be created in the order in which deposits were received.
We only warrant work from us, not third-party providers. This includes hosting companies, domain services, and email services.
Delays: Illness, injury, or other events beyond WB’s control such as theft, fire, computer failure, and Acts of God may result in a delay of unpredictable length.
Delinquency: WB reserves the right to remove web pages or the entire site from viewing on the Internet until final donation payment is made. If case collection proves necessary, the client agrees to pay all fees incurred in that process.
SOURCE FILES
Unless otherwise stated in our contract, charges for design work do not cover the release of copyrighted design files including indd, psd, png or any other source files. If the client requires these files, they will be subject to a separate quote or a ‘buy-out’ charge.
MISCELLANEOUS
LIMITATION OF LIABILITY
The members of the Board of Trustees may not under any circumstances be held liable for liabilities of this Ministry excepting any liability defined within the Bylaws. All people and persons dealing with this Ministry may address only funds and assets of Foundation for Noöspheric Consciousness for the payment of any claim, debt, judgment, obligation, as well as of any “money,” that may become due and payable in any way regarding Foundation for Noöspheric Consciousness. All actions, claims, and suits MUST be adjudicated in the Tribunals of Foundation for Noöspheric Consciousness as set forth in the Declaration of Charter/Bylaws of Foundation for Noöspheric Consciousness, A Private Spiritual Church Ministerial Association.
Member agrees they used Foundation for Noöspheric Consciousness’s services at their own risk and that Programs are only an educational service being provided. Member releases Foundation for Noöspheric Consciousness, its contributing members, ministers, directors, trustees, contracted workers, and the like (sometimes referred to as “Releasees”), and related entities (as well as the venue where the Program(s) are being held, if applicable) from any and all damages that may result from any claims arising from any Agreements, all actions, causes of action, contracts, claims, suits, costs, demands and damages of whatever nature or kind in law or in equity arising from my participation in the Programs. Member accepts any and all risks, foreseeable or unforeseeable. Member agrees that Foundation for Noöspheric Consciousness will not be held liable for any damages of any kind resulting from or arising from including but not limited to; direct, indirect, incidental, special, negligent, consequential, or exemplary damages happening from the use or misuse of Foundation for Noöspheric Consciousness’s services or enrollment in the Program. Foundation for Noöspheric Consciousness assumes no responsibility for errors or omissions that may appear in any of the program materials.
NON-DISPARAGEMENT
The Member agrees and accepts that the only venue for resolving such a dispute shall be in the venue set forth herein below. The Member agrees that they neither will engage in any conduct or communications with a third party, public or private, designed to disparage the other. Neither Member nor any of Ministry’s contributing members, ministers, directors, trustees, contracted workers, and the like will directly or indirectly, in any capacity or manner, make, express, transmit speak, write, verbalize or otherwise communicate in any way (or cause, further, assist, solicit, encourage, support or participate in any of the foregoing), any remark, comment, message, information, declaration, communication or other statements of any kind, whether verbal, in writing, electronically transferred or otherwise, that might reasonably be construed to be derogatory or critical of, or negative toward, Foundation for Noöspheric Consciousness or any of its programs, contributing members, ministers, directors, trustees, contracted workers, advisors, agents and the like or representatives.
INDEMNIFICATION
Member shall defend, indemnify, and hold harmless Foundation for Noöspheric Consciousness, Ministry’s contributing members, associates, ministers, trustees, contractors, related entities, affiliates, and successors from and against any and all liabilities and expense whatsoever – including without limitation, claims, damages, judgments, awards, settlements, investigations, costs, attorneys fees, and disbursements – which any of them may incur or become obligated to pay arising out of or resulting from the offering for sale, the sale, and/or use of the product(s), excluding, however, any such expenses and liabilities which may result from a breach of this Agreement or sole negligence or willful misconduct by Ministry, or any of its contributing members, ministers, associates, contractors, trustees, affiliates or successors. Member shall defend Ministry in any legal actions, regulatory actions, or the like arising from or related to this Agreement. Member recognizes and agrees that all of the Ministry’s contributing members, associates, ministers, contractors, trustees, affiliates, and successors shall not be held personally responsible or liable for any actions or representations of the Ministry. In consideration of and as part of Member’s donation for the right to participate in WorldBridge Media and Ministry Programs, the undersigned, your heirs, executors, administrators, successors and assigns do hereby release, waive, acquit, discharge, indemnify, defend, hold harmless and forever discharge WorldBridge Media and Ministry and its subsidiaries, principals, ministers, trustees, contractors, contributing members, agents, heirs, executors, administrators, successors, and assigns and any of the training instructors, guides, staff or students taking part in the training in any way as well as the venue where the Programs are being held (if applicable) and any of its owners, executives, agents, or staff (sometimes referred to as “Releasees”) of and from all actions, causes of action, contracts, claims, suits, costs, demands and damages of whatever nature or kind in law or in equity arising from my participation in the Programs.
NO TRANSFER OF INTELLECTUAL PROPERTY
Ministry’s Programs are copyrighted and original materials that have been provided to Members are for Member’s individual use only and a single-user license. Member is not authorized to use any of Ministry’s intellectual property for Member’s business purposes. All intellectual property, including Ministry’s copyrighted programs, course materials, and/or guided meditations, shall remain the sole property of WorldBridge Media and Foundation for Noöspheric Consciousness. No license to sell or distribute Ministry’s materials is granted or implied. By purchasing this product via donation, Member agrees (1) not to infringe any copyright, patent, trademark, trade secret, or other intellectual property rights, (2) that any Confidential Information shared by the Ministry is confidential and proprietary, and belongs solely and exclusively to the Ministry, (3) Ministry agrees not to disclose such information to any other person or use it in any manner other than in discussion with the Ministry. Further, by purchasing and Ministry product(s) via donation, Member agrees that if Member violates, or displays any likelihood of violating, any of Member’s Agreements contained in this paragraph, the Ministry will be entitled to injunctive relief to prohibit any such violations and to protect against the harm of such violations.
INDEPENDENT CONTRACTOR STATUS
Nothing in this Agreement is to be construed as creating a partnership, venture alliance, or any other similar relationship. Each party member shall be an independent contractor in its performance hereunder and shall retain control over its personnel and the manner in which such personnel performs hereunder. In no event shall such persons be deemed contractor of the other party by virtue of participation or performance hereunder.
FORCE MAJEURE
In the event that any cause beyond the reasonable control of either Party Member, including without limitation acts of God, war, curtailment or interruption of transportation facilities, threats or acts of terrorism, State Department travel advisory, labor strike or civil disturbance, make it inadvisable, illegal, or impossible, either because of unreasonable increased costs or risk of injury, for either WorldBridge Media or Ministry to perform its obligations under this Agreement, the Ministry’s performance shall be extended without liability for the period of delay or inability to perform due to such occurrence.
SEVER ABILITY/WAIVER
If any provision of this Agreement is held to be invalid or unenforceable, the remaining provisions shall nevertheless continue in full force. The failure of either Party Member to exercise any right provided for herein will not be deemed a waiver of that right or any further rights hereunder.
ASSIGNMENT
Member may not assign this Agreement without the express written consent of the Foundation for Noöspheric Consciousness.
MODIFICATION
Foundation for Noöspheric Consciousness may modify the terms of this Agreement at any time. All modifications shall be posted on the associated website and members shall be notified.
TERMINATION
Foundation for Noöspheric Consciousness is committed to providing all Members with a positive experience. By purchasing a product via donation, Member agrees that the Ministry may, at its sole discretion, terminate this Agreement, and limit, suspend, or terminate Member’s participation in the Project(s) without refund or forgiveness of monthly payments if Member becomes disruptive to Ministry or other Members, Member fails to follow the Program guidelines, is difficult to work with, impairs the participation of the other members in the Program or upon violation of the terms as determined by Ministry. The member will still be liable to pay the total contract amount.
VENTURE AND JURISDICTION
Excepting chain of title on all land titles, all business, and affairs of the Foundation for Noöspheric Consciousness Church remains exclusively within the jurisdiction of the Laws of Nature and Natures God and Ecclesiastical Law as defined, interpreted, and adjudicated by the designated committees and Tribunals of Foundation for Noöspheric Consciousness. Venue and jurisdiction are solely within Ecclesiastical Courts or Tribunals of Foundation for Noöspheric Consciousness, and all hearings, proceedings, and trials must be recorded in the records of the Ecclesiastical Court/Tribunal of Foundation for Noöspheric Consciousness. All other courts of any jurisdiction foreign to the Courts/Tribunals of Foundation for Noöspheric Consciousness lack personal or subject matter jurisdiction to hear or decide any matter of Ecclesiastical Law of Foundation for Noöspheric Consciousness.
The eternal Covenant of the Undersigned with the Creator remains paramount in all matters. As it is written: “… we ought to obey God rather than man”, Acts 5:29; and “No man can serve two masters: for either he will hate the one, and love the other; or else he will hold to the one, and despise the other. Ye cannot serve God and mammon.”, Matt. 6:24.
With the intent of living in peace with all people and living beings in the Kingdom of God, each Trustee and each minister is established as an Ecclesiastical Emissary with neutral, non-engaged, status, and is not involved in any manner with any disputes, conflicts, wars, and declarations of war powers involving any other parties.
By the authority of the Laws of Nature and between each Trustee of Foundation for Noöspheric Consciousness and members, all Trustees possess such absolute rights and powers as authority for:
- Utilizing freely the dominion given to man over the animals of the Earth and without interference or sanction from any source, all-natural substances as sacraments, for health, healing, and other purposes in accordance with our faith placed in Nature and Natures God.
- Issuing for all members of Foundation for Noöspheric Consciousness any permits, licenses, certificates of membership, certificates of ordination, diplomas, certificates of training, or other documents deemed beneficial to Trustees, Ministers, or other members of the Private Ministerial Association within the jurisdiction of Ecclesiastical Law.
- Creating, preserving, maintaining inviolate, and providing full and unalloyed protection and immunity of every kind whatsoever for all who seek spiritual sanctuary within, and abide on the soil of, any land, buildings, and dwellings of Foundation for Noöspheric Consciousness, under the exclusive venue and jurisdiction of the Ecclesiastical Law of Foundation for Noöspheric Consciousness. Said protection and immunity secure inviolate all rights regarding privacy, security, and safety of the person, possessions, papers, and effects of guests and all household dwellers against the intrusion of any kind from any source.
INTERPRETATION, DISPUTES, CLAIMS, AND EQUITABLE RELIEF
It is expressly declared that this Ministry, which is established in accordance with the Laws of Nature and Natures God, Ministry Ecclesiastical Law, the law of man, the Constitution(s) and section 508c1a of title 26 of the United States Code and any equivalent code within any of the several states of the United States of America is an unincorporated private entity.
The Private Ministerial Association, Foundation for Noöspheric Consciousness, and the aforesaid Private Association shall conduct business in the private domain as a Faith-Based Organization with all protections afforded by the Universal Declaration of Human Rights (UDHR), the U.S. Constitution, The Constitutions of the several States, the Canadian Charter of Rights, and by law.
All interpretations shall be under the Laws of God as interpreted and adjudicated by the Tribunals of Foundation for Noöspheric Consciousness. For guidance, all concerned parties, including dispute resolution committees, arbitration tribunals, and courts with jurisdiction granted, may consult appropriate court rulings concerning integrated auxiliaries of a Ministry of this type.
Member understands that, since The Association is protected by the First and Fourteenth Amendments to the U.S. Constitution, it is outside the jurisdiction and authority of Federal and State Agencies and Authorities concerning any and all complaints or grievances against The Association members or other staff persons. All rights of complaints or grievances will be settled by an Association designee, committee, or tribunal and will be waived by the member for the benefit of The Association and its members. By interacting with any content, free or purchased via donation, from WorldBridge Media or Ministry, Member agrees to these guidelines that we have sought sufficient education to determine that this is the course of action Member wants to take for him/herself.
CONTACT US
If you have any questions, concerns, or complaints about these Terms & Conditions, please contact Foundation for Noöspheric Consciousness:
- By email: info@worldbridgemedia.com
- By visiting this page on our website: https://worldbridgemedia.com/contact/
These Terms and Conditions supersede all previous representations, contracts, understandings, or agreements unless specifically agreed otherwise by both Parties, in writing.
We reserve the right to revise these terms and conditions at any time.